Terms of Service

These terms govern your use of the web3one.in website and the engagement framework between you and Web3One Tech Labs LLP. Specific client engagements are governed by a signed Master Services Agreement (MSA) or Statement of Work (SOW), which takes precedence over these general terms.

1. Website use

The Web3One website is provided for informational purposes. You may view and share its content. You may not scrape, republish, or represent our content as your own.

2. No warranty on website content

We try to keep information accurate, but the website is provided “as is” without warranties. Engagements are defined by signed contracts — not by website copy.

3. Engagement framework

Every paid engagement is governed by a Statement of Work that defines:

• Scope of deliverables
• Fixed or milestone-based pricing
• Timeline and acceptance criteria
• Payment schedule (typically 50% kick-off, 50% delivery, or 4 × 25% milestones)
• Intellectual property assignment (usually full transfer to client on final payment)
• Confidentiality and mutual NDA

No work begins until the SOW is countersigned and the initial payment is received.

4. Intellectual property

Unless otherwise specified in the SOW, all work product delivered to you — source code, smart contracts, designs, documentation — becomes your exclusive property on final payment. We retain the right to showcase the project in our portfolio (subject to any NDA) and to reuse generic, non-confidential engineering patterns, libraries, and tools we developed before or in parallel with the engagement.

5. Payments

Invoices are raised by Web3One Tech Labs LLP, payable in INR via bank transfer, USD via wire transfer, or USDC for international clients. Invoices are due within 7 days of issuance unless otherwise agreed. Late payments may delay delivery milestones.

6. Client responsibilities

Engagements assume timely client feedback, reasonable access to stakeholders, and provision of required assets, credentials, and information. Significant delays in client response may shift the delivery timeline — we’ll always communicate this clearly rather than silently slipping.

7. Scope changes

Out-of-scope requests during an engagement are handled via a written change order with updated pricing and timeline. We don’t bury scope creep in invoices or quietly refuse — we’ll flag it explicitly.

8. Limitation of liability

Our aggregate liability under any engagement is capped at the total fees paid under the relevant SOW. We are not liable for indirect or consequential damages. Smart contracts are provided subject to independent audit — we strongly recommend third-party audits for any contract handling material value.

9. Termination

Either party may terminate an engagement for material breach with 14 days’ written notice and an opportunity to cure. On termination, the client pays for work completed through the termination date; work product completed and paid for is handed over.

10. Governing law

These terms are governed by the laws of India. Disputes are subject to the exclusive jurisdiction of the courts of New Delhi, India. International engagements may specify alternative governing law and arbitration clauses in the SOW.

11. Contact

For contract questions or to request our template MSA and SOW:
Web3One Tech Labs LLP
New Delhi, India
info@web3one.in

These are plain-language general terms. They are not a substitute for a signed engagement contract and are not legal advice. Always review and negotiate the specific SOW for your project.